NOTICE TO RECEIVE SEALED BIDS
The City of Chattahoochee, FL will receive sealed bids for construction
services for the following project: Chattahoochee Southside Senior
Center (CDBG-CV grant funded). This project consists of converting
an old school building into a senior center, along with related site work.
A 5% bid bond is required. Completion date for this project will be 300
days from the date of the Notice to Proceed. Liquidated damages for
failure to complete the project on the specified date will be set at
$200.00 per day.
There will be a mandatory pre-bid meeting on September 20, 2023
at 9:30 a.m. (Eastern Time) at the City Hall Council Chambers, 22
Jefferson Street, Chattahoochee, FL 32324. Digital copies of the bid
documents can be obtained free of charge from BARNETT FRONCZAK
BARLOWE & SHULER ARCHITECTS, 2074 Centre Pointe Blvd, Suite
#200, Tallahassee, FL 32308. For bid documents or questions, please
contact Doug Shuler dshuler@bfbsa.com, 850-224-6301, or Claire
Varnedoe cvarnedoe@bfbsa.com.
Bidders shall comply with all applicable State and local laws concerning
licensing registration and regulation of contractors doing business in
the State of Florida. The bid must conform to Section 287.134 Florida
Statutes, on discriminatory vendors. Pursuant to section 287.133(2)(a),
F.S., a person or affiliate, as defined in section 287.133(1), F.S., who has
been placed on the convicted vendor list following a conviction for a
public entity crime may not submit a bid, proposal, or reply on a
contract to provide any goods or services to a public entity; may not
submit a bid, proposal, or reply on a contract with a public entity for the
construction or repair of a public building or public work; may not
submit bids, proposals, or replies on leases of real property to a public
entity; may not be awarded or perform work as a contractor, supplier,
subcontractor, or consultant under a contract with any public entity; and
may not transact business with any public entity in excess of thirty-five
thousand dollars ($35,000) for a period of 36 months following the date
of being placed on the convicted vendor list. The Bidder warrants that
neither it nor any of its affiliates is currently on the convicted vendor list.
The Bidder shall disclose if it or any of its affiliates is placed on the
convicted vendor list. Bidder must also be eligible to receive federally
funded contracts.
Bids will be received until 3:00 p.m. (EST) on October 13, 2023 at City
Hall, 22 Jefferson Street (Post Office Box 188), Chattahoochee, FL
32324. Bids will be opened and read aloud immediately following the
deadline at the same location, with the process open to public
attendance. Please indicate on the envelope that this is a SEALED BID,
for “Southside Senior Center CDBG-CV”. All Bids shall remain firm
for a period of sixty days after the opening. Bids received after the
deadline will not be accepted. The City accepts no responsibility for any
expense related to preparation or delivery of proposals, reserves the
right to reject any or all proposals, to waive technical errors and
informalities, and to accept the proposal which, in its judgment, best
serves the public interest. The City is an equal opportunity/drug-free
employer/procurer.
1t: 9/14
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GENE OPHEIM, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 261 YEAR OF ISSUANCE: 2021
DESCRIPTION OF PROPERTY: LOTS 1 & 2, BLK D, PLANTERS SUBDIVISION. OR 369 P 926. OR 377 P 1366 OR 395 P 683. OR 400 P 41
PARCEL ID NUMBER: 2-34-3N-2W-0280-0000D-0010
NAME IN WHICH ASSESSED: HEIRS OF MATTIE SHIVERS
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GENE OPHEIM, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 811 YEAR OF ISSUANCE: 2021
DESCRIPTION OF PROPERTY: OR 473 P 1229 NW1/4 OF SW1/4 SECT. 7-2N-1W.
PARCEL ID NUMBER: 3-07-2N-1W-0000-00320-0000
NAME IN WHICH ASSESSED: ESTATE OF WASH HATCHER
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GENE OPHEIM, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 873 YEAR OF ISSUANCE: 2021
DESCRIPTION OF PROPERTY: OR 820 P 1828 OR 679 P 970; OR 675 P 200; OR 671 P 1493 OR 417 P 274 BEGIN AT THE NEC OF THE SW 1/4 OF THE SE 1/4 OF SECTION 12-2N-2W AND RUN S 89 DEG 57’01» W 738.00 FT; S 00 DEG 09’53» E 738.00 FT; N 89 DEG 57’01» E 738.00 FT;N 00 DEG 09’53» W 738.00 FT TO THE P.O.B.
PARCEL ID NUMBER: 3-12-2N-2W-0000-00431-0100
NAME IN WHICH ASSESSED: TURTLE SHELL LLC
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GENE OPHEIM, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 1288 YEAR OF ISSUANCE: 2021
DESCRIPTION OF PROPERTY: OR 868 P 760 OR 453 P 981, OR 466 P 1243 LOT 7 BLOCK P BURMAH HEIGHTS.
PARCEL ID NUMBER: 3-01-2N-4W-0860-0000P-0070
NAME IN WHICH ASSESSED: 5T WEALTH PARTNERS LLC
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GENE OPHEIM, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 1367 YEAR OF ISSUANCE: 2021
DESCRIPTION OF PROPERTY: OR 849 P 1005 OR 232 P 243 OR 223 P 642 LOT 5 BLK «F» SHELFER HEIGHTS.
PARCEL ID NUMBER: 3-11-2N-4W-0960-0000F-0050
NAME IN WHICH ASSESSED: JANICE ELAINE HARRIS; CHAUNDA FORD
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GENE OPHEIM, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 1676 YEAR OF ISSUANCE: 2021
DESCRIPTION OF PROPERTY: OR 853 P 1732 OR 540 P 1281 OR 540 P 565 OR 512 P 1405 LOT 2, BLOCK A, OF PINE CREST SUBDIVISION. OR 293 P 188
PARCEL ID NUMBER: 3-26-2N-5W-1191-0000A-0020
NAME IN WHICH ASSESSED: LENVONTAE BROWN & KALELIA WALKER
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GADSDEN COUNTY, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 42 YEAR OF ISSUANCE: 2017
DESCRIPTION OF PROPERTY: OR 607 P 2027 OR 255 P 357; OR 560 P 1546 LOT 101 TORREYA HEIGHTS.
PARCEL ID NUMBER: 1-33-4N-6W-0020-00000-1010
NAME IN WHICH ASSESSED: WILFRIO & CLAIMENE CHALME
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GADSDEN COUNTY, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 57 YEAR OF ISSUANCE: 2017
DESCRIPTION OF PROPERTY: OR 504 P 1501 OR 482 P 266 OR 424 P 1011 LOT 70, EDWARDS ADDITION
PARCEL ID NUMBER: 1-33-4N-6W-0050-00000-0700
NAME IN WHICH ASSESSED: ESTATE OF KING BAKER
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GADSDEN COUNTY, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 98 YEAR OF ISSUANCE: 2017
DESCRIPTION OF PROPERTY: OR 233 P 850 BEGIN 290 FT S AND 630 FT E OF NWC OF NE1/4 OF SE1/4., RUN E 420 FT., N 210 FT; WEST 420 FT; SOUTH 210 FT TO THE P.O.B. IN SECTION 10-3N-1W.
PARCEL ID NUMBER: 2-10-3N-1W-0000-00411-0900
NAME IN WHICH ASSESSED: JOHNNIE JACKSON C/O ANGELA CAULEY
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GADSDEN COUNTY, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 815 YEAR OF ISSUANCE: 2017
DESCRIPTION OF PROPERTY: OR 32, P. 143 BEGIN 413 FT. N. OF SEC OF W1/2 OF NE1/4 OF NW1/4 RUN W. 194.8 FT., N. 137 FT., E. 114.8 FT., N. 228.54 FT., E. 80 FT., S. 365.54 FT. TO P.O.B. IN SECTION 3-3N-6W. OR 487 P 1298
PARCEL ID NUMBER: 2-03-3N-6W-0000-00213-0800
NAME IN WHICH ASSESSED: JOSEPH GISSENDANER, JACKSON GISSENDANER, DOUGLAS MAY AND STEPHANIE MAY
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GADSDEN COUNTY, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 848 YEAR OF ISSUANCE: 2017
DESCRIPTION OF PROPERTY: OR 408 P 1388; COMM AT THE SEC OF S 1/2 OF THE NW 1/4 OF THE SE 1/4; THENCE N 88 DEG 22 MIN 18 SEC W 266.97 FT; N 33 DEG 35 MIN 41 SEC W 98.55 FT; N 42 DEG 56 MIN 00 SEC W ALONG THE NE R/WAY BDNY 508.07 FT; S 47 DEG 04 MIN 00 SEC W 40.00 FT ON THE SW R/WAT BDNY; N 42 DEG 56 MIN 00 SEC W, ALONG SW R/WAY BDNY 30.00 FT MARKING THE POB. FROM POB S 47 DEG 04 MIN 00 SEC W 110.00FT; N 42 DEG 56 MIN 00 SEC W 100.00 FT; N 47 DEG 04 MIN 00 SEC E 110.0 0 FT; S 42 DEG 56 MIN 00 SEC E 100.00 FT TO POB. CONTAINING 0.253 AC M OR L. IN SECTION 3-3N-6W.
PARCEL ID NUMBER: 2-03-3N-6W-0000-00423-3100
NAME IN WHICH ASSESSED: RICHARD & EBONY COPELAND
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GADSDEN COUNTY, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 864 YEAR OF ISSUANCE: 2017
DESCRIPTION OF PROPERTY: OR 713 P 25 OR 433 P 1193 OR 100, P. 554 LOT 11, BLK. A RODDENBERRY ADDITION.
PARCEL ID NUMBER: 2-03-3N-6W-0511-0000A-0110
NAME IN WHICH ASSESSED: MARKHOR INVESTMENTS INTERNATIONAL
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GADSDEN COUNTY, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 888 YEAR OF ISSUANCE: 2017
DESCRIPTION OF PROPERTY: OR 688 P 1209 OR 633 P 312; OR 243 P 388 LOT 171, FLORIDA GRAVEL CO AND TORREYA HEIGHTS INC.
PARCEL ID NUMBER: 2-04-3N-6W-0020-00000-1710
NAME IN WHICH ASSESSED: KELLY LIVINGSTON
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GADSDEN COUNTY, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 893 YEAR OF ISSUANCE: 2017
DESCRIPTION OF PROPERTY: OR 553 P 972; OR 553 P 963 OR 553 P 969; OR 553 P 967 OR 337 P 1927–LOT 1, BLK 12, MORGAN-BOYKIN SUB., LESS W. 30 FT. ALSO: A LOT 30 BY 220 FT. RUNNING N. & S. BETWEEN LOT 4, BLK. 11, & LOT 1, BLK. 12, MORGAN-BOYKIN.
PARCEL ID NUMBER: 2-04-3N-6W-0450-00012-0010
NAME IN WHICH ASSESSED: HEIRS OF MICHAEL B MCLEROY
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GADSDEN COUNTY, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 1604 YEAR OF ISSUANCE: 2017
DESCRIPTION OF PROPERTY: N 1/2 OF LOT 7 FLETCHERTOWN OR 708 P 1073 OR 516 P 110
PARCEL ID NUMBER: 3-12-2N-4W-0000-00433-2300
NAME IN WHICH ASSESSED: HEIRS OF ROOSEVELT JONES
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28
NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN that, GADSDEN COUNTY, the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows:
CERTIFICATE NO: 1691 YEAR OF ISSUANCE: 2017
DESCRIPTION OF PROPERTY: LOT 9 BLOCK B SPRINGSIDE PARK LESS PART PER OR 160, P 76 OR 741 P 585 OR 668 P 581 OR 239 P 963 OR 158 P 255
PARCEL ID NUMBER: 3-12-2N-4W-1100-0000B-0090
NAME IN WHICH ASSESSED: SUZANNE POWELL, FORREST DAVIS, JR., DARADEE BOWEN, BETTY MORRISON, HAL A DAVIS, JR., CAROLYN ROSIER, SARA UHRING, MARY PARAMORE
Said Property being in the County of Gadsden, State of Florida. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be sold to the highest bidder at the courthouse door on the 4th Day of OCTOBER 2023 at 10:00 a.m.
Dated this 8th Day of August 2023.
NICHOLAS THOMAS
Clerk of the Circuit Court
Gadsden County, Florida
BY: ________________________________________
Ann Marie Presnell, Deputy Clerk
4t: 9/7, 9/14, 9/21, 9/28